By engaging with Unlimited Power Solutions for any product or service, you agree to the terms and conditions outlined below. These terms govern all sales, services, and installations provided by our company and may be updated at any time without prior notice. You must review these terms regularly to stay informed of any changes.
Payment Terms
Product and service payments must be made in full according to the agreed-upon payment schedule. We accept various payment methods, and any failure to meet payment obligations may result in a delay or cancellation of services. Late payments may incur additional fees as specified in the agreement.
Product Availability and Delivery
While we strive to maintain an extensive inventory of products for immediate availability, certain items may occasionally be back-ordered. In such cases, we will notify you promptly and provide an estimated delivery timeline. Delivery dates are estimates and may vary due to unforeseen circumstances beyond our control.
Installation and Services
Our team provides professional installation services for all products. We require that the installation site is prepared and compliant with any necessary building codes. Unlimited Power Solutions is not liable for delays or additional costs resulting from improper site preparation or non-compliance with regulations.
Warranty and Support
Unlimited Power Solutions offers manufacturer warranties on all products sold, including any service warranties agreed upon at the time of sale. Warranty coverage varies by product, and all warranty claims must be made per the manufacturer’s policy. We are committed to ongoing support and maintenance for all systems we install, ensuring they perform optimally.
Liability
Unlimited Power Solutions will not be liable for indirect, incidental, or consequential damages from our products or services. Our liability is limited to the cost of the products or services provided. In cases of faulty installation or product defects, we will work to rectify the issue within a reasonable timeframe.
Cancellation and Refund Policy
Cancellations of services or orders must be made in writing and are subject to approval. Refunds will be considered case-by-case, and certain products or services may be non-refundable once delivered or installed. Service cancellations may incur additional charges depending on the stage of service completion.
Governing Law
These terms and conditions shall be governed by and construed per the laws of the State of California. Any disputes arising under or in connection with these terms will be subject to the exclusive jurisdiction of the courts in California.